【正文】 altered without the prior consent of the Employer. 2 The Employer General Obligations The Employer shall provide the Site and shall pay the Contractor in accordance with Clause 13. Access to and The Employer shall grant the Contractor right of access to, and Possession of the possession of, the Site within the time stated in the Appendix to Site Tender. Such right and possession may not be exclusive to the Contractor. If the Contractor suffers delay and/or incurs Cost from failure on the part of the Employer to grant right of access to or possession of the Site, the Contractor shall give notice to the Employer’s Representative. After receipt of such notice the Employer’s Representative shall proceed in accordance with SubClause to agree or determine: (a) Any extension of time to which the Contractor is entitled under FIDIC 1995 14 / 58 SubClause , and (b) The amount of such Cost plus reasonable profit, which shall be added to the Contract Price, And shall notify the Contractor accordingly. Permit, Licences The Employer shall, at the request and cost of the Contractor, assist him or Approvals in applying for permits, licences or approvals, which are required for any part of the Works, for delivery (including clearance through customs) of Plant, Materials and Contractor39。s Documents made by or on behalf of the Contractor shall (as between the parties) Remain the property of the Contractor. The Employer may, at his cost, copy, use and municate any such documents (including making and using modifications) for the purposes of pleting, operating, maintaining, altering, adjusting and repairing the Works. They shall not, without the Contractor’s consent, be used, copied or municated to a third party by the Employer or the Employer’s Representative for other purposes. Contractor39。s Proposal. Documents on Site The Contractor shall keep on the Site one plete set of the documents forming the Contract, the Construction Documents, Variations, other munications given or issued under SubClause and the documents mentioned in SubClause . The Employer, the Employer39。 FIDIC 1995 12 / 58 (g) The Schedules。 (e) The Conditions of Contract, Part II。s Requirements。 (b) The Letter of Acceptance。 the version which is in the ruling language named in the Appendix to Tender shall prevail. The language for day to day munications shall be as stated in the Appendix to Tender. Contract Agreement Either party shall, if requested by the other party, execute a Contract Agreement, in the form annexed with such modifications as may be necessary to record the Contract. The costs of stamp duties and similar charges imposed by law shall be borne by the Employer. Priority of The documents forming the Contract are to be taken as mutually Documents explanatory of one another. If there is an ambiguity or discrepancy in The documents, the Employer39。s priced offer to the Employer for the Works, as accepted by the Letter of Acceptance. “Appendix to Tender”, means the pleted appendix prised in the Tender. “Contractor’s Proposal” means the preliminary design submitted with the Tender, as included in the Contract. “Schedules” means the information and data submitted with the Tender, as included in the Contract. “Schedule of Payments” means the Schedule designated as such (if any), referred to in SubClause . “Letter of Acceptance” means the formal acceptance by the Employer of the Tender. FIDIC 1995 7 / 58 “Contract Agreement” means the contract agreement (if any) referred to in SubClause . Persons “Employer” means the person named as such in the Appendix to Tender and the legal successors in title to such person, but not (except with the content of the Contractor) any assignee of such person. “Contractor” means the person whose Tender has been accepted by the Employer and the legal successors in title to such person, but not (except with the content of the Employer) any assignee of such person. “Employer’s Representative” means the person appointed by the Employer to act as Employer’s Representative for the purposes of the Contract and named as such in the Appendix to Tender, or other person appointed from time to time by the Employer and notified as such to the Contractor. “Contractor’s Representative” means the person (if any) named as such in the Contract or other person appointed from time to time by the Contractor under SubClause . “Subcontractor” means any person named in the Contract as a subcontractor, manufacturer or supplier for a part of the Works or any person to whom a part of the Works has been subcontracted in accordance with SubClause , and the legal successors in title to such person, but not any assignee of such person. “Dispute Adjudication Board” means the person or persons named as such in the Contract or other person or persons appointed from time to time under SubClause . Dates, Times and Periods “Base Date” means the date 28 days prior to the latest date for submission of the Tender for acceptance by the Employer. (Latest date) FIDIC 1995 8 / 58 “Effective Date” means the date on which the Contract entered into legal force and effect. “Commencement Date” means the date on which the Contractor receives the notice to mence issued by the Employer’s Representative under SubClause . “Time for Completion” means the time for pleting the Works or a Section (as the case may be), and passing the Tests on Completion, as stated in the Appendix to Tender (or as extended under SubClause ), calculated from the Commencement Date. “Contract Period” means the period from the Commencement Date to the d