【正文】 Permit, Licences The Employer shall, at the request and cost of the Contractor, assist him or Approvals in applying for permits, licences or approvals, which are required for any part of the Works, for delivery (including clearance through customs) of Plant, Materials and Contractor39。s Proposal. Documents on Site The Contractor shall keep on the Site one plete set of the documents forming the Contract, the Construction Documents, Variations, other munications given or issued under SubClause and the documents mentioned in SubClause . The Employer, the Employer39。 (e) The Conditions of Contract, Part II。 (b) The Letter of Acceptance。s priced offer to the Employer for the Works, as accepted by the Letter of Acceptance. “Appendix to Tender”, means the pleted appendix prised in the Tender. “Contractor’s Proposal” means the preliminary design submitted with the Tender, as included in the Contract. “Schedules” means the information and data submitted with the Tender, as included in the Contract. “Schedule of Payments” means the Schedule designated as such (if any), referred to in SubClause . “Letter of Acceptance” means the formal acceptance by the Employer of the Tender. FIDIC 1995 7 / 58 “Contract Agreement” means the contract agreement (if any) referred to in SubClause . Persons “Employer” means the person named as such in the Appendix to Tender and the legal successors in title to such person, but not (except with the content of the Contractor) any assignee of such person. “Contractor” means the person whose Tender has been accepted by the Employer and the legal successors in title to such person, but not (except with the content of the Employer) any assignee of such person. “Employer’s Representative” means the person appointed by the Employer to act as Employer’s Representative for the purposes of the Contract and named as such in the Appendix to Tender, or other person appointed from time to time by the Employer and notified as such to the Contractor. “Contractor’s Representative” means the person (if any) named as such in the Contract or other person appointed from time to time by the Contractor under SubClause . “Subcontractor” means any person named in the Contract as a subcontractor, manufacturer or supplier for a part of the Works or any person to whom a part of the Works has been subcontracted in accordance with SubClause , and the legal successors in title to such person, but not any assignee of such person. “Dispute Adjudication Board” means the person or persons named as such in the Contract or other person or persons appointed from time to time under SubClause . Dates, Times and Periods “Base Date” means the date 28 days prior to the latest date for submission of the Tender for acceptance by the Employer. (Latest date) FIDIC 1995 8 / 58 “Effective Date” means the date on which the Contract entered into legal force and effect. “Commencement Date” means the date on which the Contractor receives the notice to mence issued by the Employer’s Representative under SubClause . “Time for Completion” means the time for pleting the Works or a Section (as the case may be), and passing the Tests on Completion, as stated in the Appendix to Tender (or as extended under SubClause ), calculated from the Commencement Date. “Contract Period” means the period from the Commencement Date to the date 365 days after the date on which the whole of the Works shall have been pleted as certified by the Employer’s Representative under Clause 10 (or as extended under SubClause ). “day” means a calendar day and “year” means 365 days. Tests and Completion “Tests on Completion” means the tests specified in the Contract and designated as such, and any other such tests as may be agreed by the Employer’s Representative and the Contractor or instructed as a Variation, which are to be carried out before the Works or any Section are taken over by the Employer. “TakingOver Certificate” means a certificate issued under Clause 10. “Tests after Completion” means the tests specified in the Contract and designated as such, which are to be carried out after the Works or any Section are taken over by the Employer. “Performance Certificate” means the certificate issued by the Employer39。s Decision Expiry of Dispute Adjudication Board39。s Equipment Insurance against Injury to Persons and Damage to Property Insurance for Workers General Requirements for Insurances 19 FORCE MAJEURE Definition of Force Majeure Effect of Force Majeure Event Contractor39。s Care of the Works Employer39。 Retention Money Statement at Completion FIDIC 1995 4 / 58 Application for Final Payment Certificate Discharge Issue of Final Payment Certificate Cessation of Employer39。s Superintendence Contractor’s Personnel Disorderly Conduct 7 PLANT, MATERIALS AND WORKMANSHIP Manner of Execution Delivery to Site Inspection Testing Rejection Ownership of Plant and Materials 8 COMMENCEMENT, DELAYS AND SUSPENSION Commencement of Works Time for Completion Extension of Time for Completion Delays Caused by Authorities FIDIC 1995 3 / 58 Rate of Progress Liquidated Damages for Delay Suspension of Work Consequences of Suspension Payment for Plant and Materials in Event of Suspension Prolonged Suspension Resumption of Work 9 TESTS ON COMPLETION Contractor39。s Obligations Setting Out Quality Assurance Site Data Matters Affecting the Execution of the Works Unforeseeable SubSurface Conditions Access Route Right