【文章內(nèi)容簡介】 , the way of payment:1, party a shall pay 40% of the total cost of the contract, namely ____ yuan (rmb) to party b, party b received the money after the start of design.2. party b shall provide plete design draft. after confirmation by party a, the total amount of the total cost shall be paid.three. design time:1, party b shall provide plete design draft in __ working days.2, party b shall plete the design work of party a pany missioned in _____ years __ month __ day (delay time by party a reason, work time should be postponed).four. the responsibilities and obligations of the two parties:1, party b shall, according to the requirements of party a to finish the related work on time.2, party a has the responsibility to fully cooperate with party b to carry out the work stipulated in this contract and provide relevant information according to the needs of party b. party a is responsible for the consequences caused by party a39。s delay in the required information.3. party a shall provide plete design information before the start of the design, due to party a39。s provision of inplete information and changes in content.for structural changes, party a shall pay the corresponding cost of design changes.4. after party b receives the plete design information of party a, it is designed to facilitate the determination of the style of party a, and party b begins to design the first draft after the style is determined.5, party a has the right to put forward amendments to the works designed by party b. the first draft party a can make a structural modification. after the first draft is determined, the structural modifications should be made. party a shall pay the corresponding cost separately.6. the consequences of the delay due to the amendment of party a shall be borne by party a.7, due to the loss caused by post production by party a alone, the loss caused by problems in the design of the product is borne by party b. the legal liability caused by copyright, for the economic disputes shall be borne by party a..8. during the course of the project, party b is attached to the brand of party a and shall not sign any form of cooperation agreement with the customer in the identity of party b.five. the agreement on intellectual property rights:1, party b has the copyright of the works pleted by the design. after the settlement of all the fees designed by party a, party b may transfer the copyright of the works to party a.2. before party a has not paid all the cost of the design, the copyright of the works designed by party b shall be attributed to party b, and party a does not have any right to the work.3. party a shall have the right to investigate the legal liability of party a if it uses or amends the works designed by party b before the payment is not paid.six. liability for breach of contract:1, party a terminates the contract before the pletion of the first draft of the design work. the prepaid expenses have no right to request the return. if a party terminates the contract after the pletion of the first draft of party b39。s work, it shall pay the full design fee.2. if party b terminates the contract without proper reasons, the fees charged shall be returned to party a.seven, if a party or a party has a dispute over the performance of this contract, it shall be settled amicable through negotiation. if either party fails to negotiate, any party a and b can submit it to the beijing arbitration mission for arbitration.eight, the contract is effective from the date of signature by gai zhang and both parties. the contract is two copies in one form. each party has one contract signed by the other party (gai zhang), which has the same legal effect.nine. if there is no matter in this contract, the two parties shall jointly discuss and supplement the contract. the contents of the supplement and modification are equally valid to this contract.party a: party b:(signature seal) (signature seal)date: date:地址：電話：乙方：地址：電話：依據(jù)《中華人民共和國合同法》和有關(guān)法規(guī)的規(guī)定，乙方接受甲方的委托，就委托設(shè)計(jì)事項(xiàng)，雙方經(jīng)協(xié)商一致，簽訂本合同，信守執(zhí)行：一、委托事項(xiàng)：二、付款方式：甲方需在合同簽訂之時(shí)支付總費(fèi)用的40% ，即____元(人民幣)給乙方，乙方收到甲方的款項(xiàng)后開始設(shè)計(jì)。乙方提供完整的設(shè)計(jì)稿，甲方確認(rèn)后,應(yīng)當(dāng)即付清總費(fèi)用的全部余款。三、設(shè)計(jì)時(shí)間：乙方需在__個工作日內(nèi)提供比較完整的設(shè)計(jì)稿。乙方需在_____年__月__日完成甲方公司委托的設(shè)計(jì)工作 (由甲方原因耽誤的時(shí)間，完稿時(shí)間應(yīng)順延)。四、雙方的責(zé)任與義務(wù)：乙方應(yīng)按甲方要求按質(zhì)按量按時(shí)完成相關(guān)設(shè)計(jì)工作。甲方有責(zé)任全力配合乙方開展本合同所規(guī)定的工作，并根據(jù)乙方需要提供相關(guān)資料。由于甲方提供所需資料延誤時(shí)間造成的后果，由甲方承擔(dān)。甲方應(yīng)在設(shè)計(jì)開始前提供完整的設(shè)計(jì)資料，由于甲方提供資料不完整、內(nèi)容改動而造成的設(shè)計(jì)結(jié)構(gòu)改動，甲方須另行支付相應(yīng)的設(shè)計(jì)改動費(fèi)用。乙方收到甲方的完整設(shè)計(jì)資料后進(jìn)行部分小樣設(shè)計(jì)以方便甲方確定風(fēng)格，風(fēng)格確定后乙方開始進(jìn)行初稿設(shè)計(jì)。甲方有權(quán)對乙方所設(shè)計(jì)的作品提出修改意見，初稿甲方可提出一次結(jié)構(gòu)上的修改，初稿確定后的結(jié)構(gòu)修改，甲方須另行支付相應(yīng)費(fèi)用。因甲方修改，延誤時(shí)間造成的后果，由甲方承擔(dān)。由于后期制作造成的損失由甲方獨(dú)自承擔(dān)，由于制作物設(shè)計(jì)出現(xiàn)問題造成的損失由乙方承擔(dān)。 因版權(quán)、文責(zé)所引發(fā)的法律責(zé)任，經(jīng)濟(jì)糾紛由甲方承擔(dān)。設(shè)計(jì)項(xiàng)目期間乙方掛靠于甲方品牌之中，不得以乙方身份單獨(dú)與客戶簽訂任何形式的合作協(xié)議。五、知識產(chǎn)權(quán)約定：乙方對設(shè)計(jì)完成的作品享有著作權(quán)。甲方將委托設(shè)計(jì)的所有費(fèi)用結(jié)算完畢后，乙方可將作品著作權(quán)轉(zhuǎn)讓給甲方。甲方在未付清所有委托設(shè)計(jì)費(fèi)用之前，乙方設(shè)計(jì)的作品著作權(quán)歸乙方，甲方對該作品不享有任何權(quán)利。甲方在余款未付清之前擅自使用或者修改使用乙方設(shè)計(jì)的作品而導(dǎo)致的侵權(quán)，乙方有權(quán)追究其法律責(zé)任。六、違約責(zé)任：甲方在設(shè)計(jì)作品初稿完成前終止合同，其預(yù)付的費(fèi)用無權(quán)要求退回；甲方在乙方作品初稿完成后終止合同的，應(yīng)當(dāng)支付全額的設(shè)計(jì)費(fèi)用。乙方如無正當(dāng)理由提前終止合同，所收取的費(fèi)用應(yīng)當(dāng)全部退回給甲方。七、甲乙雙方如因履行本合同發(fā)生糾紛，應(yīng)當(dāng)友好協(xié)商解決，協(xié)商不成的，甲乙雙方任何一方均可向北京仲裁委員會提請仲裁解決。八、本合同自甲乙雙方簽字蓋章之日起生效，本合同一式兩份，雙方各持對方簽字（蓋章）合同一份，具有同等的法律效力。九、本合同如有未盡事宜，由甲乙雙方共同討論補(bǔ)充或修改。補(bǔ)充和修改的內(nèi)容與本合同具有同等效力。甲方： 乙方：（簽字蓋章） （簽字蓋章）廣告合同協(xié)議篇十甲方：____________________ 乙方：____________________聯(lián)系人：__________________ 聯(lián)系人：__________________電話：____________________ 電話：____________________傳真：____________________ 傳真：____________________地址：_